This page was read by OCR. Text can misread numbers, dates or table columns. Check the PDF before quoting or interpreting it. Redacted areas remain redacted.
for employees placed by or on behalf of the Contractor, will state that such Contractor is an equal opportunity
employer and maintains a drug-free workplace. (e) Notices, advertisements and solicitations placed in
accordance with federal law, rule or regulation shall be deemed sufficient for the purpose of meeting these
requirements.
(2) The Contractor will include the provisions above in every subcontract or purchase order over $10,000, so
that the provision will be binding upon each Subcontractor or vendor.
For the purposes of this section, “drug-free workplace” means a site for the performance of work done in
connection with a specific contract awarded to a Contractor, the employees of whom are prohibited from
engaging in the unlawful manufacture, sale, distribution, dispensation, possession or use of any controlled
substance or marijuana during the performance of the contract.
4. ANTITRUST: By entering into a contract, the Contractor conveys, sells, assigns, and transfers to NNRHA
all rights, title and interest in and to all causes of action it may now have or hereafter acquire under the
antitrust laws of the United States and the Commonwealth of Virginia relating to the particular goods or
services purchased or acquired under said contract.
5. APPLICABLE LAW AND COURTS: This solicitation and any contract resulting from this solicitation
shall be governed in all respects by the laws of the Commonwealth of Virginia and any litigation with respect
thereto shall be brought in the courts of the City of Newport News, VA. The Contractor shall comply with all
applicable federal, state, local laws and regulations. The Contractor shall procure any permits and licenses
required for its business as the services to be provided by it hereunder.
6. ASBESTOS: Whenever and wherever during the course of performing any work under this contract, the
Contractor discovers the presence of asbestos or suspect that asbestos is present; the Contractor shall stop the
work immediately, secure the area, notify the building owner and await positive identification of the suspect
material. During the downtime in such a case, the Contractor shall not disturb any surrounding surfaces but shall
protect the area with suitable dust covers. In the event the Contractor is delayed due to the discovery of asbestos
or suspected asbestos, then a mutually agreed extension of time to perform the work shall be allowed the
Contractor but without additional compensation due to the time extension.
7. ASSIGNMENT OF CONTRACT: A contract shall not be assignable by the Contractor in whole or in part
without the written consent of NNRHA.
8. AUDIT: The Contractor shall retain all books, records, and other documents relative to this contract for five
(5) years after final payment, or until andited, whichever is sooner. The agency, its authorized agents, and/or
state and federal auditors shall have full access to and the right to examine any of said materials during said
period.
9. AVAILABILITY OF FUNDS: It is understood and agreed between the parties herein that NNRHA shall be
bound hereunder only to the extent of the funds available or which may hereafter become available for the
purpose of this agreement.
10. AWARD OF CONTRACT: Formal and informal bids and proposals will be awarded to the lowest
tesponsible and responsive bidder(s) or most suitable offeror. The quality of the articles to be supplied, their
conformity with the specifications, their suitability to the requirements of NNRHA, and the delivery terms
will be taken into consideration in making an award. Length of time for delivery as well as price may be
considered in awarding of the contract. NNRHA is not liable for any cost incurred by the Contractor prior to
issuance of a contract.
NNRHA also reserves the right to make multiple awards, by line item, lot, award based on overall lowest
pricing, cancel or reject any or all bids or proposals, in whole or in part, to waive informalities and to delete
Marshall Courts Phase VII Demolition
IFB #MCP7D-09-24 Page 2 af 16
ATTACHMENT “B” Initial:Jump to an indexed page (88 of 88)